LEASE-LEASEBACK SUBLEASE AGREEMENT. Dated as of ***Insert Data Here*** Between. Sacramento City Unified School District. and. ***Insert Data Here***

Transcription

1 Business Services Contracts Office th Avenue Sacramento, CA (916) Gerardo Castillo, Chief Business Officer Kimberly Teague, Contract Specialist LEASE-LEASEBACK SUBLEASE AGREEMENT Dated as of ***Insert Data Here*** Between Sacramento City Unified School District and ***Insert Data Here*** ***Insert Data Here***

2 LEASE-LEASEBACK SUBLEASE AGREEMENT ***Insert Data Here*** This LEASE-LEASEBACK SUBLEASE AGREEMENT ( Sublease ) is entered into on ***Insert Data Here***, between ***Insert Data Here***, ( Contractor ), a California corporation and licensed general contractor as lessee, and the Sacramento City Unified School District), a California public school district (the Owner ) as lessor. RECITALS: WHEREAS, pursuant to Section et seq. of the Education Code, the Owner may enter into leases and agreements relating to real property and buildings used by the Owner; and WHEREAS, the Owner deems it essential for its own governmental purpose to finance certain improvements described in Exhibit A of the Lease-Leaseback Agreement entered into between the Owner and Contractor dated ***Insert Data Here***, for the ***Insert Data Here*** Project (the Lease-Leaseback Agreement ; and the Project ) and situated on the Site described in Exhibit A of the Site Lease dated the same date between the Owner and Contractor related to the Project (the Site Lease ). The land described in the Site Lease is herein referred to as the Site ; and WHEREAS, pursuant to Section of the Education Code, the Owner is leasing the Site to Contractor pursuant to the Site Lease in consideration of Contractor subleasing the Site, including the Project, to the Owner pursuant to the terms of this Sublease; and WHEREAS, the Owner owns the Site and pursuant to the Lease-Leaseback Agreement has prepared, adopted, and had approved plans and specifications for the completion of the Project pursuant to law as required by Section of the Education Code; and WHEREAS, the Owner and Contractor agree to mutually cooperate now or hereafter, to the extent possible, in order to sustain the intent of this Sublease and the bargain of both parties hereto, and to provide payments pursuant to this Sublease. WITNESSETH: In consideration of the mutual covenants hereinafter set forth, the Owner and Contractor agree as follows: Section 1. Sublease. Contractor hereby leases and subleases to the Owner, and the Owner hereby leases and subleases from Contractor, the Site, including any real property improvements now or hereafter affixed thereto in accordance with the provisions herein for the full term of this Sublease. Hereinafter, reference to Contractor means Contractor and Contractor s assigns for those rights, interests, and obligations that may be assigned by Contractor. The purpose of this Sublease is (1) for the Owner to have necessary access to and use of the Site at such times and in such a manner as will not impede the construction of the Project; (2) for the Owner to obtain needed financing for the Project; and (3) after the completion of the Project but prior to the expiration or termination of the Sublease, for the Owner to enjoy beneficial occupancy of the Site and the completed Project. During the term of the Sublease, Owner and its agents, employees and invitees may enter into and upon the Site and the Project at all reasonable times necessary for conduct of Owner business thereon. During construction, the Owner shall not unduly disturb, or unreasonably interfere with Contractor s work on the Project and related improvements to the Site. Following completion of the Project, the Owner shall enjoy full and undisturbed use of the Site. Section 2. Term. The terms and conditions of this Sublease shall become effective upon the authorized execution of this Sublease by the parties. The term of the Sublease shall be coterminous with the term of the Lease-Leaseback Agreement. Upon termination, the parties respective interests hereunder automatically ended and released, and 1

3 title to the Site and Project automatically and fully vested in the Owner. Section 3. Representations, Warranties and Covenants of the Owner. The Owner represents and warrants to Contractor that: (a) The Owner is a public school district, duly organized and existing under the Constitution and laws of the State with authority to enter into this Sublease and to perform all of its obligations hereunder. (b) The Owner s governing body has duly authorized the execution and delivery of this Sublease and further represents and warrants that all requirements have been met and procedures followed to ensure its enforceability. (c) The execution, delivery, and performance of this Sublease do not and will not result in any breach of or constitute a default under any indenture, mortgage, contract, agreement, or instrument to which the Owner is a party by which it or its property is bound. (d) There is no pending or, to the knowledge of the Owner, threatened action, or proceeding before any court or administrative agency that will materially adversely affect the ability of the Owner to perform its obligations under this Sublease. (c) The Project and the Site are essential to the Owner in the performance of its governmental functions and their estimated useful life to the Owner exceeds the term of this Sublease. (d) The Owner shall take such action as may be necessary to include all Sublease payments in its annual budget and annually to appropriate an amount necessary to make such Sublease payments. (e) The District shall not abandon the Site for the use for which it is currently required by the Owner and, to the extent permitted by law, the Owner shall not seek to substitute or acquire property to be used as a substitute for the use for which the Site is maintained under the Sublease; and (f) The Owner shall not allow any hazardous materials or substances to be used or stored on, under, or about the Site. Section 4. Representations and Warranties of Contractor. Contractor represents and warrants to the Owner that: (a) Contractor is duly organized, validly existing and in good standing as a contractor and licensed contractor under the laws of the State, with full corporate power and authority to lease and own real and personal property; (b) Contractor has full power, authority and legal right to enter into and perform its obligations under this Sublease, and the execution, delivery and performance of this Sublease have been duly authorized by all necessary corporate actions on the part of Contractor and do not require any further approvals or consents; (c) The execution, delivery, and performance of this Sublease do not and will not result in any breach of or constitute a default under any indenture, mortgage, contract, agreement, or instrument to which Contractor is a party by which it or its property is bound; (d) There is no pending or, to the knowledge of Contractor, threatened action, or proceeding before any court or administrative agency that will materially adversely affect the ability of Contractor to perform its obligations under this Sublease; (e) Contractor will not mortgage or encumber the Site or the Sublease or assign this Sublease or its rights to receive Sublease payments hereunder, except as permitted herein. 2

4 Section 5. Construction/Acquisition (a) The Owner has entered into the Lease-Leaseback Agreement and the Site Lease with Contractor in order to acquire and construct the tenant improvements identified as the Project. The cost of the acquisition, financing, construction, and installation of the Project, in addition to the beneficial use of the Site afforded to the Owner under this Sublease, is determined by the Total Sublease Amount as set forth in Article 4 of the Lease- Leaseback Agreement. (b) In order to ensure that moneys sufficient to pay all costs will be available for this purpose when required, the Owner shall maintain on deposit in its general or other appropriate fund, and shall annually appropriate funds sufficient to make all Sublease payments which become due to Contractor under this Sublease. Section 6. Sublease Payments (a) The Owner shall pay Contractor lease payments (the Sublease Payments and each individually a Sublease Payment ) monthly, at the office of Contractor or to such other person or at such other place as Contractor may from time to time designate in writing. Notwithstanding the foregoing, after the Date of Completion, or at such earlier time that the Owner has exercised its right to the beneficial use of any portion of the Project, the Contractor agrees to provide an amount equal to a portion of the Total Sublease Amount, specifically ***INSERT DATA HERE*** $ (the Financed Amount ) which cannot be paid by the Owner and must be financed. In consideration for the Financed Amount, the Owner agrees to pay the Contractor in monthly payments over the course of ***INSERT DATA HERE*** months (the Financed Sublease Payments ) which shall be deemed the financing portion of the Total Sublease Amount and shall be referenced herein as the Financing Lease. The amount of each monthly payment shall be the principal of the Financed Amount, divided by the number of months set forth above, plus an interest rate equal to the current Bank of America prime interest rate of 4.0% of the remaining Financed Amount. Without penalty, the Owner shall have the right to terminate the Financing Lease consistent with Section 22 of this Sublease. Upon final payment, including the Financing Lease, by the Owner, the beneficial use as between the Contractor as landlord, and the Owner as tenant, shall terminate and all right, title, and interest to all improvements constructed by the Contractor shall automatically vest in the Owner. Contractor agrees to execute any documents that may be necessary or otherwise required to validate the vesting of title as set forth herein. To the extent there are any inconsistent provisions in any of the Contract Documents with the payment and financing provisions herein, subject to any sublease abatement as set forth in Section 8, the provisions herein shall supersede any such inconsistent financing and payment provisions. (b) Contractor agrees that satisfactory progress pursuant to the time schedule required pursuant to the Contract and of the construction pursuant to the time schedule required pursuant to the Contract (the Time Schedule ) shall be conditions precedent to the making of Sublease Payments by the Owner. The determination of whether the Time Schedule has been adequately adhered to shall be made in accordance with the General Conditions of the Contract ( General Conditions ). If the Owner determines that pursuant to the Time Schedule, the work required to be performed prior to a given Sublease Payment has not been met, the Owner shall not be required to make that scheduled Sublease Payment. Once the Owner has determined that the work scheduled to be completed prior to the Sublease Payment in question has been completed, the Owner shall make the Sublease Payment corresponding to completion of such work. (c) In accordance with the General Conditions, the Owner shall retain an amount equal to 5% of each Sublease Payment. Release of the retention and the final Sublease Payment shall be made in the manner described in the General Conditions. (d) The obligation of the Owner to pay Sublease Payments hereunder shall constitute a current expense of the Owner and shall not in any way be construed to be a debt of the Owner in contravention of any applicable constitutional or statutory limitations or requirements concerning the creation of indebtedness by the Owner, nor shall anything contained herein constitute a pledge of the general tax revenues, funds, or moneys of the Owner. 3

5 (e) Extension of Lease Term. If the Project is not completed by the Date for Completion set forth in Agreement, then the Lease Term shall be extended by such period of time between the Date for Completion and the date that the Project is finally complete, except that District shall be relieved of its obligation to make Sublease Payments during such extended term. This Section shall not amend or modify any lease extension under Section 6(a). Section 7. Fair Rental Value. Sublease Payments shall be paid by the Owner in consideration of the right of possession of, and the continued quiet use and enjoyment of, the Project and the Site during this Sublease. The parties hereto have agreed and determined that such total rental is not in excess of the fair rental value of the Project and the Site. In making such determination, consideration has been given to the fair market value of the Project and the Site, other obligations of the parties under this Sublease (including, but not limited to, costs of maintenance, taxes and insurance), the uses and purposes which may be served by the Project and the Site and the benefits therefrom which will accrue to the Owner and the general public, the ability of the Owner to make additions, modifications and improvements to the Project and the Site which are not inconsistent with the Lease-Leaseback Agreement and which do not interfere with Contractor s work on the Project and Site. Section 8. Sublease Abatement. In addition to delay of Sublease Payments provided in Section 6, above, Sublease Payments due hereunder with respect to the Project shall be subject to abatement prior to the commencement of the use of the Project or during any period in which, by reason of material damage to or destruction of the Project or the Site there is substantial interference with the use and right of possession by the Owner of the Project and the Site or any substantial portion thereof. For each potential incident of substantial interference, decisions to be made on: i) whether or not abatement shall apply; ii) the date upon which abatement shall commence; iii) the applicable portion of Sublease Payments to be abated and; iv) the concluding date of the particular abatement shall all be subject to determinations by the Owner in concert with its insurance provider. Contractor s right to dispute these decisions is not impaired. The amount of abatement shall be such that the Sublease Payments paid by the Owner during the period of Project restoration do not exceed the fair rental value of the usable portions of the Site. In the event of any damage or destruction to the Project or the Site, this Sublease shall continue in full force and effect. This Section shall not amend or modify any lease extension under Section 6(a). Section 9. Use of Site and Project. The Owner will not use, operate, or maintain the Site or Project improperly, carelessly, in violation of any applicable law or in a manner contrary to that contemplated by this Sublease. The Owner shall provide all permits and licenses, if any, necessary for the operation of the Project. In addition, the Owner agrees to comply in all respects (including, without limitation, with respect to the time, maintenance and operation of the Project) with laws of all jurisdictions in which its operations involving the Project may extend and any legislative, executive, administrative, or judicial body exercising any power or jurisdiction over the Site or the Project; provided, however, that the Owner may contest in good faith the validity or application of any such law or rule in any reasonable manner which does not, in the opinion of Contractor, adversely affect the estate of Contractor in and to the Site or the Project or its interest or rights under this Sublease. Upon completion of the Project or severable portions thereof, as defined in the General Conditions, Contractor shall provide the Owner with quiet use and enjoyment of the Site without suit or hindrance from Contractor or its assigns, subject to reasonable interference from ongoing construction operations on any remaining portion of the Site under construction by Contractor. Section 10. Contractor s Inspection/Access to the Site. The Owner agrees that Contractor and any Contractor representative shall have the right at all reasonable times to enter upon the Site or any portion thereof to construct and improve the Project, to examine and inspect the Site and the Project and to exercise its remedies pursuant to Section 21 of this Sublease. The Owner further agrees that Contractor and any Contractor representative shall have such rights of access to the Site as may be reasonably necessary to cause the proper maintenance of the Site and the Project in the event of failure by the Owner to perform its obligations hereunder. Section 11. Project Acceptance. The Owner shall acknowledge final inspection and completion of the Project by executing a Certificate of Acceptance and recording a Notice of Completion in accordance with the General Conditions. The validity of this Sublease will not be affected by any delay in or failure of completion of the Project. 4

6 Section 12. Lease-Leaseback Agreement and Site Lease. The Lease-Leaseback Agreement and Site Lease are incorporated herein in their entirety by this reference. Section 13. Alterations and Attachments. All permanent additions and improvements that are made to the Project shall belong to and become the property of Contractor, subject to the provisions of Sections 21 and 22 hereof. Separately identifiable attachments added to the Project by the Owner shall remain the property of the Owner. At Contractor s request, the Owner agrees to remove the attachments and restore the Project to substantially as good condition as when acquired and constructed, normal wear and tear excepted, in the event of failure by the Owner to perform its obligations hereunder. Section 14. Physical Damage; Public Liability Insurance. The Contractor and the Owner shall maintain such damage and public liability insurance policies with respect to the Project and the Site as are required of them by the Lease-Leaseback Agreement. Upon vesting in Owner of all right, title, and interest to all improvements constructed by the Contractor as set forth in the Contract Documents, Owner shall be responsible for insuring the property. Section 15. Taxes. The Owner shall keep the Project and the Site free and clear of all levies, liens, and encumbrances and shall pay all license fees, registration fees, assessments, charges, and taxes (municipal, state, and federal) if applicable, which may now or hereafter be imposed upon the ownership, leasing, renting, sale, possession, or use of the Project and the Site, excluding, however, all taxes on or measured by Contractor s income. Section 16. Indemnity. In addition to the indemnification set forth in Article X of the Lease-Leaseback Agreement, to the extent permitted by law, and with the exception of the Contractor s responsibilities as Contractor under the Lease-Leaseback Agreement, the Owner shall, with respect to the Project and the Site, indemnify Contractor against and hold Contractor harmless from any and all claims, actions, suits, proceedings, costs, expenses, damages, and liabilities, including attorneys fees, arising out of, connected with or resulting from any acts of omission or commission by the Owner s employees and agents or claims resulting from incidents or occurrences involving the financing of the Project and Lease-Leaseback aspects of the Project and third parties on the Site, including without limitation, the construction, possession, use or operation of the Project and further, the Owner agrees, to the extent the law allows, to indemnify Contractor against and hold Contractor harmless from and against any and all claims, actions, suits, proceedings, cost, expenses, damages, and liabilities, including attorney s fees, arising out of, connected with or resulting from the clean-up of any hazardous materials or toxic wastes from the Site or the Project; provided, however, that the Owner shall not be required to indemnify Contractor in the event that such liability or damages are caused by the negligence or intentional misconduct of Contractor. Section 17. Events of Default. The term Event of Default, as used in this Sublease means the occurrence of any one or more of the following events: (a) the Owner fails to make any unexcused Sublease Payment (or any other payment) within 15 days after the due date thereof; (b) the Owner or the Contractor fails to perform or observe any other covenant, condition or agreement to be performed or observed by it hereunder and such failure to either make the payment or perform the covenant, condition or agreement is not cured within 10 days after written notice thereof by the other Party; (c) the discovery by a Party that any statement, representation or warranty made by the other Party in this Sublease, or in any document ever delivered by that other Party pursuant hereto or in connection herewith is misleading or erroneous in any material respect; (d) a Party becomes insolvent, is unable to pay its debts as they become due, makes an assignment for the benefit of creditors, applies or consents to the appointment of a receiver, trustee, conservator or liquidator of the Party or of all or a substantial part of its assets, or a petition for relief is filed by the Party under federal bankruptcy, insolvency or similar laws. Section 18. Remedies on Default. Upon the happening of any Event of Default, the non-defaulting Party may exercise any and all remedies available pursuant to law or in equity or granted pursuant to this Sublease. Notwithstanding any provisions to the contrary herein, Contractor shall not under any circumstances have the right to accelerate the Sublease Payments that fall due in future Sublease periods or otherwise declare any Sublease Payments not then in default to be immediately due and payable. Section 19. Non-Waiver. No covenant or condition to be performed by the Owner or Contractor under this Sublease can be waived except by the written consent of the other party. Forbearance or indulgence by the Owner 5

7 or Contractor in any regards whatsoever shall not constitute a waiver of the covenant or condition in question. Until complete performance by the Owner or Contractor of said covenant or condition, the other party shall be entitled to invoke any remedy available to it under this Sublease or by law or in equity despite said forbearance or indulgence. Section 20. Assignment. Without the prior written consent of Contractor, the Owner shall not (a) assign, transfer, pledge, or hypothecate this Sublease, the Project and the Site, or any part thereof, or any interest therein, or (b) sublet or lend the use of the Project or any part thereof, except as authorized by the provisions of the California Civic Center Act, Education Code Section et seq. Consent to any of the foregoing prohibited acts applies only in the given instance and is not a consent to any subsequent like act by the Owner or any other person. Contractor shall not assign its obligations under this Sublease with the exception of its obligation to issue default notices and to convey or reconvey its interest in the Project and Site to the Owner upon full satisfaction of the Owner's obligations hereunder; however, Contractor may assign its right, title and interest in this Sublease, the Sublease Payments and other amounts due hereunder and the Project in whole or in part to one or more assignees or subassignees at any time without the consent of the Owner. No assignment shall be effective as against the Owner unless and until the Owner is so notified in writing. The Owner shall pay all Sublease Payments due hereunder pursuant to the direction of Contractor or the assignee named in the most recent assignment or notice of assignment. During the Sublease term, the Owner shall keep a complete and accurate record of all such assignments. Subject always to the foregoing, this Sublease inures to the benefit of, and is binding upon, the heirs, legatees, personal representatives, successors, and assigns of the parties hereto. Section 21. Ownership. The Project is and shall at all times be and remain the sole and exclusive property of Contractor, and the Owner shall have no right, title, or interest therein or thereto except as expressly set forth herein. Section 22. Sublease Prepayments/Purchase Option. (a) Sublease Prepayments. At any time during the term of this Sublease, the Owner may make Sublease Prepayments to the Contractor of the Sublease Payments including the Financial Sublease Payments ( Sublease Prepayments ). No Sublease Prepayments requested by Contractor may be made by the Owner in an amount which exceeds the aggregate true cost to Contractor of the work on the Project completed to the date Contractor submits the request for a Sublease Prepayment less the aggregate amount of: (1) all Sublease Payments previously made by the Owner to Contractor; (2) all Sublease Prepayments previously made by the Owner to the Contractor; (3) all amounts previously retained pursuant to Section 22(a)(3), below, from Sublease Prepayments previously made by the Owner to Contractor (unless Contractor shall have previously substituted securities for such retained amounts pursuant to Section 22(a)(3)); and (5) the retention for such Sublease Prepayment pursuant to Section 22(a)(3) hereof. Contractor must submit evidence that the conditions precedent set forth in Section 22(a) (1), below, have been met. In the event Owner elects to make Sublease Prepayments, the Prepayment Price, contemplated in Section 22(b), below, shall be adjusted accordingly. (1) The following are conditions precedent to any Sublease Prepayments made to Contractor pursuant to a request of Contractor: (a) Satisfactory progress of the construction of the Project pursuant to the time schedule required pursuant to the General Conditions shall have been made as determined in accordance therewith. (b) Contractor shall also submit to the Owner (i) duly executed conditional lien releases and waivers (in the form provided in California Civil Code Section 3262) from Contractor and all Subcontractors, consultants and other persons retained by Contractor in connection with the Project, whereby such persons conditionally waive all lien and stop notice rights against the Owner, the Project and the Project site with respect to the pending Sublease Prepayment to be made by the Owner, (ii) duly executed unconditional lien releases and waivers (in the form provided in California Civil Code Section 3262) from Contractor and all subcontractors, consultants and other persons retained by Contractor in connection with the Project, whereby such persons unconditionally and irrevocably waive all lien and stop notice rights against the Owner, the 6

8 Project and the Project site with respect to all previous Sublease Prepayments made by the Owner, and (iii) any other items that Contractor may be required to collect and distribute to the Owner pursuant to the terms and provisions of the Contract. Contractor shall promptly pay all amounts due to each subcontractor, consultant and other person retained by Contractor in connection with the Project no later than 10 days after Contractor s receipt of a Sublease Prepayment from the Owner. (2) The determination of whether satisfactory progress of the construction pursuant to the Time Schedule has occurred shall be made by the Owner in accordance with the General Conditions. If the Owner determines that pursuant to the Time Schedule the work required to be performed, as stated in Contractor s Sublease Prepayment request, has not been substantially completed, then Contractor shall not be eligible to receive the requested Sublease Prepayment. (3) The Owner shall retain an amount equal to 5% of each Sublease Prepayment ( retention ) made at Contractor s request. Contractor shall have the right, as delineated in the General Conditions, to substitute securities for any retention withheld by the Owner, pursuant to the provisions of Public Contract Code Section At any time after 50% of the work has been completed, if the Governing Board of the Owner finds that satisfactory progress is being made, then it may make any of the remaining Sublease Prepayments in full. Section 23. Release of Liens. (a) If the Owner is not in default hereunder, the Owner shall be granted options to purchase not less than the entire Project in as-is condition. The Prepayment Price at any given time shall be an amount equal to the final GPC, as it may be revised from time to time, less the sum of any Sublease Payments and/or Sublease Prepayments made by the Owner prior to the date on which the Owner elects to exercise its option under this Section. The Owner may thereupon terminate this Sublease. Following the purchase option date, Owner shall retain all rights to any claim or warranty arising under the Contract. (a) Notwithstanding Section 22 hereof, upon the Owner executing a Certificate of Acceptance and filing a Notice of Completion on the Project, as such term is defined herein and in the General Conditions, Contractor or its assignee and the Owner shall release Contractor s leasehold interest in the Project upon termination of the Financing Lease. (b) Contractor shall authorize, execute, and deliver to the Owner all documents reasonably requested by the Owner to evidence (i) the release of any and all liens created pursuant to the provisions of this Sublease and the Site Lease, and (ii) any other documents required to terminate the Site Lease and this Sublease. Section 24. Severability. If a court of competent jurisdiction shall hold any provision of this Sublease invalid or unenforceable, such holdings shall not invalidate or render unenforceable any other provision of this Sublease, unless elimination of such provision materially alters the rights and obligations embodied in this Sublease. Section 25. Entire Agreement. This Sublease, the Site Lease, the Lease-Leaseback Agreement, and the Contract Documents that make up the Contract constitute the entire agreement between Contractor and the Owner, and it shall not be amended, altered, or changed except by a written agreement signed by the parties hereto. Section 26. Notices. Any notices or filings required to be given or made under this Sublease shall be served, given, or made in writing upon the Owner or Contractor, as the case may be, by personal delivery or registered mail (with a copy sent via fax or regular mail) to the respective addresses given below, or at such address as such party may provide in writing from time to time. 7

9 If to Owner: Sacramento City Unified School District Attn: Kimberly Teague, Contract Specialist th Avenue Sacramento, CA If to Contractor: ***INSERT DATA HERE*** Name, Title, and Address Section 27. Headings. The captions or headings in this Sublease are for convenience only and in no way define, limit or describe the scope or intent of any provisions or Sections of this Sublease. Section 28. Time. Time is of the essence in this Sublease and each and all of its provisions. Section 29. Sublease Interpretation. This Sublease and the rights of the parties hereunder shall be governed by and construed in accordance with the laws of the State of California. Section 30. Execution in Counterparts. This Sublease may be simultaneously executed in several counterparts, each of which shall be an original and all of which shall constitute but one and the same instrument. Section 31. Terms Not Defined. Capitalized terms used in this Sublease that are not defined shall have the same meaning as in the Lease-Leaseback Agreement or General Conditions. Section 32. Exhibits Incorporated. All Exhibits attached to this Sublease are hereby incorporated into the Sublease by this reference as if set forth in full. The parties hereto have executed this Sublease by their authorized officers as of the dates so indicated under their respective signatures. OWNER SACRAMENTO CITY UNIFIED SCHOOL DISTRICT CONTRACTOR ***INSERT DATA HERE*** By: Gerardo Castillo Chief Business Officer By: Signature Date Print Name/President Date By: Signature Print Name/Corporate Secretary Date 8

10 EXHIBIT A SCHEDULE OF SUBLEASE PAYMENTS The term of this sublease shall commence as of the date shown on page 1 of this Sublease. Financed Sublease payments shall be paid monthly in accordance with the Contract Documents and the total Sublease Payments made shall not exceed the amount of the final Total Sublease Amount defined in Article 4 of the Lease-Leaseback Agreement. Each month Contractor shall provide Owner with an itemized summary reflecting the percentage of work performed and signed off on by the Owner s DSA Inspector or other designated employee. The Sublease Payments shall be commensurate with the amount of work performed, invoiced, and signed off on by the DSA Inspector to date, all in accordance with the procedures set forth in the General Conditions. Notwithstanding the foregoing, the term of this Sublease may be extended and payment options may be modified by written agreement of the parties hereto. 9